Tenant Default. In addition to any other default of Tenant pursuant to the Lease, any of the following shall be deemed to be a material default of Tenant if such failure continues for more than thirty (30) days after written notice from Landlord; provided that if such failure cannot reasonably be cured within a thirty (30) day period, a default shall not be deemed to have occurred if Tenant promptly commences such cure within said period of thirty (30) days, and thereafter diligently pursues the same to completion: # Tenant’s failure to perform its material obligations under this Agreement; # Tenant’s failure to diligently prosecute the construction of the Tenant Improvements; # Tenant’s failure to pay Tenant’s Contractor or other parties involved in the construction of the Tenant Improvements in accordance with the Construction Contract (or other contract applicable to such party); # Tenant’s material default under the Construction Contract or any other contracts in connection with construction of the Tenant Improvements to which Tenant is a party which would allow the Contractor (or the other party to such contract) to either terminate the Construction Contract (or other contract) or cease work; or # the cessation of construction of the Tenant Improvements after commencement thereof for reasons other than Force Majeure Events.

Tenant Indemnification. Tenant shall indemnify, defend by counsel reasonably acceptable to Landlord, protect and hold Landlord, Wilson Meany, L.P. and their respective directors, shareholders, investment managers, partners, lenders, members, managers, contractors, affiliates, employees, trustees, principals, beneficiaries, officers, mortgagees and agents (each a “Landlord Party” and collectively, the “Landlord Parties”) harmless from and against any and all claims, liabilities, losses, costs, loss of rents, liens, damages, injuries or expenses, including reasonable attorneys’ and consultants’ fees and court costs, demands, causes of action, or judgments (collectively, “Losses”), directly or indirectly arising out of or related to: # the use or occupancy or manner of use or occupancy of the Premises (including the Roof Top Area) by Tenant or any Tenant Party; or # any injury or death of any person or damage to or destruction of property occurring in the Premises (including the Roof Top Area), from any cause whatsoever; or # any injury or death of any person or damage to or destruction of property occurring in, on or about the Building or Project or in the vicinity of the Building or Project, including the Common Areas and Parking Facilities, to the extent such injury, death or damage is caused by the negligence or willful misconduct of Tenant or any Tenant Parties; or # Tenant’s use of the roof of the Building pursuant to Paragraph 38; or # the installation, use, operation, maintenance, replacement and/or removal of the Generator Equipment or any portion. The foregoing indemnity by Tenant shall not be applicable to claims to the extent arising from the gross negligence or willful misconduct of Landlord. Landlord shall not be liable to Tenant and Tenant hereby waives all claims against Landlord for any injury to or death of, or damage to any person or property or business loss in or about the Premises, Building or Project by or from any cause whatsoever (other than Landlord’s gross negligence or willful misconduct) and, without limiting the generality of the foregoing, whether caused by water leakage of any character from the roof, walls, basement or other portion of the Premises, Building or Project, or caused by gas, fire, oil or electricity in, on or about the Premises, Building or Project, acts of God or of third parties, or any matter outside of the reasonable control of Landlord. The provisions of this Paragraph shall survive the expiration or earlier termination of this Lease.

Tenant Remedies. Notwithstanding anything to the contrary in this Lease, if Tenant claims that Landlord has unreasonably withheld, conditioned, or delayed its consent under this Paragraph 22 or otherwise has breached or acted unreasonably under this Paragraph 22, Tenant’s remedies shall be declaratory judgment and an injunction for the relief sought, and/or an action for compensatory monetary damages, and Tenant hereby waives all other remedies, including, without limitation, any right provided under California Civil Code Section 1995.310 or other Applicable Laws to terminate this Lease.

Tenant Rights. All awards, damages and other compensation paid on account of such condemnation shall belong to Landlord, and Tenant assigns to Landlord all rights to such awards, damages and compensation. Tenant shall not make any claim against Landlord or such authority for any portion of such award, damages or compensation attributable to damage to the Premises, value of the unexpired portion of the Lease Term, loss of profits or goodwill, leasehold improvements or severance damages. Nothing contained herein, however, shall prevent Tenant from pursuing a separate claim against the authority for relocation expenses and for the value of furnishings, equipment and trade fixtures installed in the Premises at Tenant’s expense and which Tenant is entitled pursuant to this Lease to remove at the expiration or earlier termination of the Lease Term, provided that such claim shall in no way diminish the award, damages or compensation payable to or recoverable by Landlord in connection with such condemnation.

Tenant Estoppels. The Borrowers have delivered to the Agent true, correct, accurate and complete copies of # each form of estoppel certificate sent to a Tenant of any Property and # each estoppel certificate received from a Tenant of any Property prior to the Closing Date.

Tenant Work. Notwithstanding anything to the contrary in this Exhibit C, Tenant shall be responsible for all work, construction and installation in the Expansion Space which is not designated as Landlord Work (including, but not limited to, all fixtures, furniture, equipment and other office installations). Such work shall be referred to as “Tenant Work,” and shall be at Tenant’s sole cost and expense. The Tenant Work shall be considered an alteration for purposes of the Lease, as herein amended, and shall be subject to, among others, the provisions of [Sections 6.1(b)-(d) and 6.4]4]4] thereof. Prior to commencing the Tenant Work, Tenant shall submit drawings and specifications for the Tenant Work to Landlord, showing all aspects of such work, to Landlord for Landlord’s review and approval.

Tenant Receivables. Rents due from tenants under Leases and from tenants or licensees under License Agreements and operating expenses and/or taxes payable by tenants under Leases (collectively, “Tenant Receivables”) and not collected by ​ as of Closing shall not be prorated between ​ and ​ at Closing but shall be apportioned on the basis of the period for which the same are payable and if, as and when collected, as follows:

Tenant Deposits. All tenant and licensee security deposits collected and not applied by ​ (and interest thereon if required by Law or contract) shall be transferred or credited to ​ at Closing. As of the Closing, ​ shall assume ​’s obligations related to tenant and licensee security deposits, but only to the extent they are credited or transferred to ​. Any and all deposits, bonuses or similar payments by any licensees under the License Agreements or any vendors under the Service Contracts shall be retained by ​ and not prorated or credited to ​. In the event the security deposit shall have been deposited with ​ in a form other than cash (e.g., letter of credit), ​ shall satisfy its obligations hereunder with respect to such security deposit by delivering to Escrow Agent, to be held in trust for the benefit of ​, an assignment of such security deposit to ​ with written instructions to the issuer of such deposit to transfer the same to ​, and appropriate instruments of transfer or assignment.

Tenant/Leases. As of the Effective Date, [Exhibit G] lists all tenants of the Properties and the Lease Files include all leases and amendments with such tenants. To ​’s knowledge, ​ has not entered into any License Agreement or Lease or other right relating to the use or possession of the Properties or any part thereof except for the tenants under the Leases or the occupants under the License Agreements.

Liability. It is expressly agreed that the liability of each Guarantor for the payment of the Obligations guaranteed hereby shall be primary and not secondary.