Manner of Construction. Landlord may impose, as a condition of its consent to all Alterations or repairs of the Premises, the requirement that Tenant to utilize only contractors, mechanics and materialmen approved by Landlord, such approval not to be unreasonably withheld. Tenant shall construct such Alterations and perform such repairs in compliance with any and all applicable rules and regulations of any federal, state, county or municipal code or ordinance and pursuant to a valid building permit, and issued by the city in which the Building is located. Landlord’s approval of the plans, specifications and working drawings for Tenant’s Alterations shall create no responsibility or liability on the part of Landlord for their completeness, design sufficiency, or compliance with all laws, rules and regulations of governmental agencies or authorities. All work with respect to any Alterations must be done in a good and workmanlike manner and diligently prosecuted to completion to the end that the Premises shall at all times be a complete unit except during the period of work. Tenant shall cause all Alterations to be performed

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that upon Landlord's request, Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority), if applicable. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations (or repairs), Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Diego in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations, if applicable.

Manner of Construction. Other than with respect to Cosmetic Alterations, Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors reasonably approved by Landlord, and any removal and/or restoration obligations required to be performed pursuant to the TCCs of [Section 8.5] of this Lease. If Landlord shall give its consent, the consent shall be deemed conditioned upon Tenant acquiring a permit to do the work from appropriate governmental agencies, the furnishing of a copy of such permit to Landlord prior to the commencement of the work, and the compliance by Tenant with all conditions of said permit in a prompt and expeditious manner. If such Alterations will involve the use of or disturb Hazardous Materials existing in the Premises, Tenant shall notify Landlord prior to performing such Alterations and comply with Landlord's rules and regulations concerning such Hazardous Materials, subject to Landlord's obligations set forth in [Section 29.35.5] below. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county, local or municipal laws, ordinances, rules and regulations and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority), all in conformance with Landlord's construction rules and regulations; provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord's design parameters and code compliance issues. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the "Base Building," as that term is defined below, then Landlord shall, at Tenant's expense, make such changes to the Base Building. Since all or a portion of the Project is or may become in the future certified under the LEED rating system (or other applicable certification standard) (all in Landlord's sole and absolute discretion), Tenant expressly acknowledges and agrees that without limitation as to other grounds for Landlord withholding its consent to any proposed Alteration, Landlord shall have the right to withhold its consent to any proposed Alteration in the event that such Alteration is not compatible with such certification or recertification of the Project under such LEED rating system (or other applicable certification standard). Upon Tenant's request, Landlord shall notify Tenant if Landlord is attempting to obtain or has obtained LEED certification. The "Base Building" shall include the structural portions of the Building, and the public restrooms, elevators, exit stairwells and the systems and equipment located in the internal core of the Building on the floor or floors on which the Premises is located. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to obstruct the business of Landlord or other tenants in the Project. Tenant shall retain any union trades to the extent designated by Landlord. Further, Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Francisco in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and as a condition precedent to the enforceability and validity of Landlord's consent, Tenant shall deliver to the management office for the Project a reproducible copy of the "as built" and CAD drawings of the Alterations, to the extent applicable, as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that upon Landlord's request, Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority). Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations, Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Mateo in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for Alterations that are reasonably expected to affect the “Base Building” (as defined below) only contractors, subcontractors, materials, mechanics and

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that upon Landlord's request, Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term; provided, however, that Landlord may not require Tenant to remove any Alterations which are otherwise consistent with typical tenant improvements in the biotechnology or pharmaceutical industries. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority). Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations, Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Mateo in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors reasonably approved by Landlord, and any removal and/or restoration obligations for Specialty Alterations required to be performed pursuant to the TCCs of [Section 8.5] of this Lease. If Landlord shall give its consent, the consent shall be deemed conditioned upon Tenant acquiring a permit to do the work from appropriate governmental agencies, the furnishing of a copy of such permit to Landlord prior to the commencement of the work, and the compliance by Tenant with all conditions of said permit in a prompt and expeditious manner. If such Alterations will involve the use of or disturb Hazardous Materials, Tenant shall notify Landlord prior to performing such Alterations and comply with Landlord's rules and regulations concerning such Hazardous Materials. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all Applicable Laws and pursuant to a valid building permit, issued by the City of South San Francisco (the "City") (or other applicable governmental authority), in conformance with Landlord's reasonable construction rules and regulations. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the Building Structure, other than the legal compliance work which is Landlord's obligation pursuant to the TCCs of [Section 24.1] of this Lease, then Landlord shall, at Tenant's expense, make such changes to the Base Building. The "Base Building" shall mean the Building Structure and Building Systems. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to obstruct the business of other tenants in the Project. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of Mateo in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and as a condition precedent to the enforceability and validity of Landlord's consent, Tenant shall deliver to the management office for the Project a reproducible copy of the "as built" and CAD drawings of the Alterations, to the extent applicable, as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

Tenant shall pay for all work (including, without limitation, the cost of all utilities, permits, fees, taxes, and property and liability insurance premiums in connection therewith) required to make the Alterations. Tenant shall engage responsible licensed contractor(s) approved in writing by Landlord to perform all work. Tenant shall provide Landlord advance written notice of the contractors, subcontractors, mechanics and materialmen whom Tenant proposes to engage for the work, all of which shall be licensed in the State of in which the Building is located and capable of being bonded. Landlord shall notify Tenant in writing whether Landlord approves or disapproves such contractor(s) within a reasonable period of time. All contractors and other persons shall at all times be subject to Landlord's control while in the Building. In the event the cost to construct or install the Alterations proposed by Tenant is estimated to exceed Three Hundred Thousand and 00/100 Dollars ($300,000.00), Landlord shall have the right to require that Tenant post such security for the payment of the Alterations as Landlord reasonably determines is necessary and Landlord shall also have the right to require that any such contractor engaged by Tenant shall, prior to commencing work in the Premises, provide Landlord with a performance bond and a labor and materials payment bond from a surety reasonably acceptable to Landlord in the amount of the contract price for the work naming Landlord and Tenant (and any other person designated by Landlord) as co obligees. Prior to the commencement of any Alterations, if required by Landlord, Tenant shall provide Landlord with evidence that Tenant or its general contractor carries "Builder's All Risk" insurance in form and amount approved by Landlord covering such Alterations. Under no circumstances shall Landlord be liable to Tenant for any liability, loss, cost or expense incurred by Tenant on account of Tenant's plans and specifications, Tenant's contractors or subcontractors, design of any work, construction of any work, or delay in completion of any work, however, the foregoing waiver or release of liability shall not be applicable to any liability, loss, cost or expense to the extent arising from the negligence or willful misconduct by Landlord or any of its agents, employees, affiliates, contractors, subcontractors or other representatives. In addition, Tenant acknowledges and agrees that any and all Alterations have not been expressly or impliedly required as a condition to the execution of this Lease for the use of the Premises permitted under this Lease or in lieu of payment of rent.

Tenant may, in its sole discretion and without the prior consent of Landlord, make any alterations, additions or improvements (collectively, “Alterations”) in or to the Premises. All such Alterations shall be performed by Tenant in a good and workmanlike manner and comply with all Requirements. Tenant’s contractor shall obtain all applicable building and occupancy permits required by law. Tenant agrees to indemnify Landlord and hold it harmless against any loss, liability or damage resulting from such work. Notwithstanding anything to the contrary set forth in this Lease, Landlord will not make any Alterations in or to the Premises without the prior written consent of Tenant.

materialmen selected by Tenant from a list provided and approved by Landlord, and the requirement that upon Landlord's request made at the time such Alteration(s) are approved by Landlord, Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and, if the same is required, pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority), all in conformance with Landlord's reasonable construction rules and regulations; provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord's design parameters and code compliance issues. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the "Base Building," as that term is defined below, then Landlord shall notify Tenant when approving such Alterations and, if Tenant still wishes to construct same, Landlord shall, at Tenant's expense, make such changes to the Base Building. The "Base Building" shall include the structural portions of the Building, and the public restrooms, elevators, exit stairwells and the systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to materially obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to materially obstruct the business of Landlord or other tenants in the Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County in which the Building is located in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

No alteration shall be commenced without Tenant having previously obtained all appropriate permits and approvals required by and of governmental agencies; (e)All alterations shall be performed in a skillful and workmanlike manner, consistent with the best practices and standards of the construction industry, and pursued with diligence in accordance with said Plans previously approved by Landlord and in full accord with all applicable laws and ordinances. All material, equipment, and articles incorporated in the alterations are to be new and of recent manufacture and of the most suitable grade for the purpose intended;