Example ContractsClausesmanner of exercising optionVariants
Manner of Exercising Option
Manner of Exercising Option contract clause examples
Previous results

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, subcontractors, materials, mechanics and materialmen selected by Tenant and approved by Landlord (which approval shall not be unreasonably withheld, conditioned or delayed) and the requirement that upon Landlord’s request (subject to the terms of Section 8.5 below), Tenant shall, at Tenant’s expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all Applicable Laws and, where required by Applicable Law, pursuant to a valid building permit. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations (or repairs), Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors, design professionals, service providers, suppliers and materialmen who performed such work and whose labor, supplies or services give rise to a lien under California law. In addition to Tenant’s obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant shall deliver to the Project construction manager a reproducible copy of the “as built” drawings of the Alterations in CAD format as well as copies of all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

permit, issued by the city in which the Building is located (or other applicable governmental authority). Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations, Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a notice of completion to be recorded in the office of the Recorder of the County of San Mateo in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

with contractors and/or vendors reasonably approved by Landlord; and # pursuant to plans and specifications reasonably approved by Landlord, as the case may be. Landlord’s review and approval of the plans and specifications for the Alterations shall create no responsibility or liability on the part of Landlord for their completeness, design sufficiency, or compliance with all Laws. Notwithstanding anything to the contrary contained in this Lease (including, without limitation, Section 31, below) Landlord’s consent may be conditioned, among other things, on Tenant’s removing any such Alterations at the Expiration Date and repairing and restoring the Premises and the Building to the same condition as initially delivered to Tenant. Before commencing any work, Tenant shall # give Landlord at least ten (10) days written notice of the proposed commencement of such work, # provide Landlord with the necessary certificates of insurance as required by Section 17 below, and # secure, at Tenant’s own cost and expense, a completion and lien indemnity bond, reasonably satisfactory to Landlord, for said work if reasonably required by Landlord; provided, however, that so long as Tenant is not then in monetary default under this Lease, Landlord shall not require such bond unless the cost of such Alterations are reasonably likely to exceed One Million Dollars ($1,000,000.00). Landlord shall have the right at all times to post notices of non-responsibility on the Premises and record verified copies thereof in connection with all work of any kind upon the Premises. The complete set of construction documents outlining proposed interior improvements shall be furnished to Landlord before the construction commences. An executed copy of the final building permit shall be provided to Landlord before the notice of non-responsibility shall be removed from the Premises. Tenant shall pay to Landlord a supervision fee equal to one percent (1%) of the hard cost of such Alterations to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord’s supervision of or involvement with the Alterations; provided, however, that no fee shall be charged by Landlord in connection with an Exempt Alteration. Promptly after completion of any Alterations, Tenant shall deliver to Landlord “as-built” plans and specifications (including all working drawings) for the Alterations, and cause a Notice of Completion to be recorded in the office of the Recorder of the County of Contra Costa in accordance with Section 3093 of the California Civil Code or any successor statute and furnish a copy thereof to Landlord upon recordation, and timely give all notices required pursuant to Section 3259.5 of the California Civil Code or any successor statute (failing which, Landlord may itself execute and file such Notice of Completion and give such notices on behalf of Tenant as Tenant’s agent for such purpose).

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for Alterations that are reasonably expected to affect the “Base Building” (as defined below) only contractors, subcontractors, materials, mechanics and

Tenant shall pay for all work (including, without limitation, the cost of all utilities, permits, fees, taxes, and property and liability insurance premiums in connection therewith) required to make the Alterations. Tenant shall engage responsible licensed contractor(s) approved in writing by Landlord to perform all work. Tenant shall provide Landlord advance written notice of the contractors, subcontractors, mechanics and materialmen whom Tenant proposes to engage for the work, all of which shall be licensed in the State of in which the Building is located and capable of being bonded. Landlord shall notify Tenant in writing whether Landlord approves or disapproves such contractor(s) within a reasonable period of time. All contractors and other persons shall at all times be subject to Landlord's control while in the Building. In the event the cost to construct or install the Alterations proposed by Tenant is estimated to exceed Three Hundred Thousand and 00/100 Dollars ($300,000.00), Landlord shall have the right to require that Tenant post such security for the payment of the Alterations as Landlord reasonably determines is necessary and Landlord shall also have the right to require that any such contractor engaged by Tenant shall, prior to commencing work in the Premises, provide Landlord with a performance bond and a labor and materials payment bond from a surety reasonably acceptable to Landlord in the amount of the contract price for the work naming Landlord and Tenant (and any other person designated by Landlord) as co obligees. Prior to the commencement of any Alterations, if required by Landlord, Tenant shall provide Landlord with evidence that Tenant or its general contractor carries "Builder's All Risk" insurance in form and amount approved by Landlord covering such Alterations. Under no circumstances shall Landlord be liable to Tenant for any liability, loss, cost or expense incurred by Tenant on account of Tenant's plans and specifications, Tenant's contractors or subcontractors, design of any work, construction of any work, or delay in completion of any work, however, the foregoing waiver or release of liability shall not be applicable to any liability, loss, cost or expense to the extent arising from the negligence or willful misconduct by Landlord or any of its agents, employees, affiliates, contractors, subcontractors or other representatives. In addition, Tenant acknowledges and agrees that any and all Alterations have not been expressly or impliedly required as a condition to the execution of this Lease for the use of the Premises permitted under this Lease or in lieu of payment of rent.

Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that upon Landlord's request, Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term; provided, however, that Landlord may not require Tenant to remove at the expiration or any early termination of this Lease any Tenant Improvements shown in the Approved Schematic Plans or any Alternations consistent with the improvements shown in the Approved Schematic Plan, or any Alterations which are otherwise consistent with typical tenant improvements in the biotechnology or pharmaceutical industries. Tenant shall construct such Alterations and perform

Alterations. Tenant shall not make or permit any alterations, decorations, additions or improvements of any kind or nature to the Premises or the Project, whether structural or nonstructural, interior, exterior or otherwise (“Alterations”) without the prior written consent of Landlord, said consent not to be unreasonably withheld or delayed. Landlord may impose any reasonable conditions to its consent, including, without limitation: # prior approval of the plans and specifications and contractor(s) with respect to the Alterations (provided that Landlord may designate specific contractors with respect to Building systems provided such contractors charge commercially competitive rates); # supervision by Landlord’s representative, at Tenant’s expense, of the Alterations, not to exceed three percent (3%) of the hard and soft costs of the Alteration; # proof of worker’s compensation insurance and commercial general liability insurance carried by Tenant’s contractors and subcontractors in such amounts and meeting such requirements as reasonably requested by Landlord; # delivery to Landlord of written and unconditional waivers of mechanic’s and materialmen’s liens as to the Project for all work, labor and services to be performed and materials to be furnished, signed by all contractors, subcontractors, materialmen and laborers participating in the Alterations; # delivery of permits, certificates of occupancy, “as-built” plans, and equipment manuals; and # in the case of Alterations that exceed $200,000 in the aggregate during a 12-month period, any security for performance or payment that is reasonably required by Landlord. The Alterations shall conform to Landlord’s Specifications (as defined in Exhibit B-11]) and set forth in [Exhibit B-3]3] attached hereto and made a part hereof and the requirements of federal, state and local governments having jurisdiction over the Premises, including, without limitation, the ADA, the California ADA, the OSHA General Industry Standard (29 C.F.R. Section 1910.1001, et seq.), and the OSHA Construction Standard (29 C.F.R. Section 1926.1001, et seq.) and shall be performed in accordance with the terms and provisions of this Lease and all warranties in effect and in a good and workmanlike manner using material of a quality that is at least equal to the quality designated by Landlord as the minimum standard for the Building. Notwithstanding the foregoing, Tenant shall have the right, without Landlord’s consent, to perform in the Premises any nonstructural Alteration; provided that Tenant has provided Landlord with at least ten (10) business days prior written notice of such Alteration and such Alteration # does not affect the other tenants of the Building or the Building’s mechanical, electrical, plumbing, HVAC or fire, life safety systems or the roof, foundations, exterior walls or structural portions of the Building; # does not require any other alteration, addition, or improvement to be performed in or made to any portion of the Building or Project other than the Premises; # does not materially or negatively impact the future marketability of the Building or increase the Building’s assessed value for tax purposes; # does not alter the architectural or structural integrity of the Building; # does not require a building permit; # is not visible from the exterior of the Premises; # do not include any deviations from the Specifications or any light fixtures, entry doors, interior doors, HVAC diffusers or demountable walls; and # together with any other Alterations, does not exceed a cost of $200,000 in any one Calendar Year, unless such Alterations are comprised of carpet and paint only, in which case no such limit shall not apply (provided that Tenant shall not perform such Alterations in stages in order to subvert this provision). All computer, telecommunications or other cabling, wiring and associated appurtenances (collectively, “Cabling”) installed by Tenant inside any of the interior walls of the Premises, above the ceiling of the Premises, in any portion of the ceiling plenum above or below the Premises, or in any portion of the Common Areas of the Project, including but not limited to any of the shafts or utility rooms of the Building, shall be clearly labeled or otherwise identified as having been installed by Tenant. All Cabling installed by Tenant shall comply with the requirements of the National Electric Code and any other applicable fire and safety codes. Landlord may designate reasonable rules, regulations and procedures for the performance of work in the Building and, to the extent reasonably necessary to avoid disruption to the occupants of the Project, shall have the right to designate the time when Alterations may be performed. will not unreasonably require removal of Alterations at the end of the Term such as by requiring removal of Alterations that are not specialized to Tenant’s use of the Building, do not materially and negatively impact the Building’s structure or systems or the future marketability of the Building, are not visible from the Common Areas or the exterior of the Building and are consistent with use of the Premises as a class A office building. If Landlord requires the removal of all or part of the Alterations pursuant to this Section 12.3, Tenant, at its expense, shall repair any damage to the Premises or the Project caused by such removal and restore the Premises and the Project to its condition prior to the construction of such Alterations, reasonable wear and tear excepted. If Tenant fails to remove the Alterations that Tenant is required to remove pursuant to this Section 12.3 and repair and restore the Premises and Project, then Landlord may (but shall not be obligated to) remove, repair and restore the same and the actual cost of such removal, repair and restoration together with any and all damages which Landlord actually suffers and sustains by reason of the failure of Tenant to remove, repair and restore the same, shall be charged to Tenant and paid within 30 days of demand and Landlord’s invoice or statement for the same. If Tenant reasonably requests additional documentation or information regarding the charges set forth in such invoice or statement, then Landlord shall promptly provide such documentation or information (which may be provided by email) as Landlord reasonably determines appropriate to substantiate such charges. Notwithstanding the foregoing, Tenant may remove any trade fixtures, business equipment, personal property and furniture provided that Tenant repairs any damage to the Premises resulting from the removal of such items and restores the Premises to its condition prior to the installation of such items, reasonable wear and tear excepted.

13.1Consent of Landlord. “Alterations” shall include, but are not limited to, improvements, additions, utility installations or repairs made by Tenant or its agents and contractors in, on or about the Premises or the Project. Except for Permitted Alterations (as defined below), Tenant shall not make any Alterations to the Premises without the prior written approval of Landlord, which shall not be unreasonably withheld or delayed. Provided Tenant gives Landlord not less than fifteen (15) days advance written notice of a Permitted Alteration (a “Permitted Alteration Notice”) and Tenant’s compliance with Landlord’s requirements relating to construction at the Project, Tenant shall have the right to make Permitted Alterations without Landlord’s consent. A Permitted Alterations Notice shall include a detailed description of the Permitted Alteration, the approximate date the Permitted Alteration will commence and be completed and the approximate cost of the Permitted Alteration. A “Permitted Alteration” shall mean an Alteration to the inside of the Premises (e.g., paint and carpet, communication systems, telephone and computer system wiring) that does not # involve the expenditure of more than ​, # affect the exterior appearance of the Building or the roof, # affect the Building’s electrical, plumbing, HVAC, life, fire safety or similar Building systems or the structural elements of the Building, # affect the Common Areas or parking areas or # materially adversely affect any other tenant of the Project. At the expiration of the term, Landlord may require the removal of any Alterations installed by Tenant and the restoration of the Premises and the Project to their prior condition, at Tenant's expense if, at the time of Landlord's consent, Landlord did not agree in writing that Tenant would not be obligated to remove the Alterations. Within ten (10) days after Tenant provides to Landlord a written notice requesting Landlord’s decision concerning the removal of proposed Alterations (a “Tenant Notice”), Landlord shall respond to Tenant’s request. If Landlord fails to respond to Tenant’s request within ten (10) days after Landlord receives a Tenant Notice, Tenant may give Landlord a second written notice (a “Second Notice”) again requesting Landlord’s decision concerning the removal of the Alterations. The Second Notice shall expressly state that Landlord’s failure to respond to the Second Notice within five (5) business days will be deemed Landlord’s election pursuant to this Section 13.1 of the Lease not to require Tenant to remove the Alterations at the end of the term of this Lease. If Landlord fails to respond to Tenant’s Second Notice within such five (5) business day period, Landlord shall be deemed to have elected not to require Tenant to remove the Alterations at the end of the term of this Lease. If, as a result of any Alteration made by Tenant, Landlord is obligated to comply with the Americans With Disabilities Act or any other law or regulation, and such compliance requires Landlord to make any improvement or Alteration to any portion of the Project, as a condition to Landlord's consent, Landlord shall have the right to require Tenant to pay to Landlord prior to the construction of any Alteration by Tenant the entire cost of any improvement or alteration Landlord is obligated to complete by such law or regulation. Should Landlord permit Tenant to make its own Alterations, Tenant shall use only such architect and contractor as has been reasonably approved by Landlord, and Landlord may require Tenant to provide to Landlord, at Tenant's sole cost and expense, a lien and completion bond in an amount equal to one and one-half times the estimated cost of such Alterations, to insure Landlord against any liability for mechanic's and materialmen's liens and to insure completion of the work. In addition, Tenant shall pay to Landlord a fee equal to the lesser of # the actual amount Landlord pays to its property manager to supervise such Alterations or # ​ to compensate Landlord for the overhead and other costs it incurs in reviewing the plans for the Alterations and in monitoring the construction of the Alterations (the “Landlord Fee”). If Landlord incurs architectural, engineering or other consultant’s fees in evaluating such Alterations, Tenant shall reimburse Landlord for these fees in addition to the Landlord Fee. If Tenant proposes Alterations to Landlord but subsequently elects not to construct the Alterations, and Landlord has incurred costs in reviewing Tenant’s proposed Alterations (e.g., architect’s, engineer’s or property management fees), Tenant shall reimburse Landlord for the reasonable costs incurred by Landlord within ten (10) days after written demand. Should Tenant make any Alterations without the prior approval of Landlord, or use a contractor not expressly approved by Landlord, Landlord may, at any time during the term of this Lease, require that Tenant remove all or part of the Alterations and return the Premises to the condition it was in prior to the making of the Alterations. In the event Tenant makes any Alterations, Tenant agrees to obtain or cause its contractor to obtain, prior to the commencement of any work, "builders all risk" insurance in an amount reasonably approved by Landlord, workers compensation insurance and any other insurance reasonably requested by Landlord.

provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord's design parameters and code compliance issues. If Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the "Base Building," as that term is defined below, then Landlord shall, at Tenant's expense (subject to the terms of Article 24), make such changes to the Base Building. The "Base Building" shall mean the Building Structure and Building Systems. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to obstruct the business of Landlord or other tenants in the Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of Santa Clara in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

standard materials, finishes and colors, free of all liens and encumbrances. All Alterations shall be performed by a contractor or contractors selected by Tenant and approved in writing by Landlord. Tenant shall pay to Landlord a fee equal to five percent (5%) of the cost of any such Alterations to compensate Landlord for the overhead and other costs it incurs in reviewing the plans therefor and in monitoring the construction of the Alterations. If, as a result of any Alterations made by Tenant, Landlord is obligated to comply with the Americans With Disabilities Act or any other Laws and Restrictions and such compliance requires Landlord to make any improvement or Alteration to any portion of the Building, as a condition to Landlord's consent, Landlord shall have the right to require Tenant to pay to Landlord prior to the construction of any Alteration by Tenant, the entire cost of any improvement or alteration Landlord is obligated to complete by such law or regulation. Tenant agrees to obtain or cause its contractor(s) to obtain, prior to the commencement of any work or Alterations, “builder’s all risk” insurance in an amount and with such coverages approved by Landlord and worker’s compensation insurance in the statutorily required amount(s) and evidence of all such insurance shall be furnished to Landlord prior to the performance by such contractor(s) or person(s) of any work in respect of the Premises. Landlord shall have the right to stop any work not being performed in conformance with this Lease, and, at its option, may repair or remove non-conforming work at the expense of Tenant. Tenant hereby indemnifies and holds Landlord harmless from and against any liens, encumbrances and violations of Laws and Restrictions. The filing of any lien or encumbrance, or the violation of Laws and Restrictions, shall constitute a default hereunder. The repair and indemnity obligations of Tenant hereunder, including Tenant’s obligations to repay Landlord the cost of repairing or removing Alterations, shall survive the termination of this Lease. All Alterations performed by Tenant in the Premises shall remain therein (unless Landlord directs Tenant to remove the same on termination or expiration of this Lease) and, at termination or expiration, shall be surrendered as a part thereof, except for Tenant’s usual trade furniture and equipment, if movable, installed prior to or during the Lease term at Tenant’s cost, which trade furniture and equipment Tenant shall remove in their entirety prior to the termination or expiration of this Lease, provided that if Tenant is then in default hereunder, Landlord may direct that no such trade fixtures, furniture and equipment be removed. Tenant agrees to repair any and all damage to the Premises resulting from such removal (including removal of Tenant’s Alterations directed by Landlord) or, if Landlord so elects, to pay Landlord for the cost of any such repairs forthwith after billing therefor.

Tenant shall not make or permit to be made any alterations, additions, or improvements in or to the Premises (“Alterations”) without first obtaining the prior written consent of Landlord which consent shall not be unreasonably withheld, conditioned or delayed with respect to non-structural Alterations that do not cost more than Fifty Thousand Dollars ($50,000) in any one calendar year, are not visible from outside of the Premises and do not affect the operating or life safety systems of the Building, but which consent may otherwise be withheld in Landlord' s sole discretion. Notwithstanding the foregoing, Landlord's consent shall not be required for cosmetic Alterations, such as painting, hanging pictures, and installing carpeting so long as Tenant provides Landlord not less than five (5) business days prior written notice of any such Alteration for which Tenant has engaged a third party contractor. All Alterations # must comply with all Applicable Laws, # must be compatible with the Building and its mechanical, electrical, heating, ventilating, air-conditioning and life safety systems; # must not interfere with the use and occupancy of any other portion of the Building by any other tenant or their invitees; and # must not affect the integrity of the structural portions of the Building. In addition, Landlord may impose as a condition to such consent such additional requirements as Landlord in its commercially reasonable discretion deems necessary or desirable, including, without limitation: # Tenant's submission to Landlord, for Landlord's prior written approval (not to be unreasonably withheld, conditioned or delayed), of all plans and specifications relating to the Alterations; # Landlord's prior written approval (not to be unreasonably withheld, conditioned or delayed) of the time or times when the Alterations are to be performed; # Landlord's prior written approval (not to be unreasonably withheld, conditioned or delayed) of the contractors and subcontractors performing work in connection with the Alterations (provided, however, that Tenant shall be entitled to use its own architect and general contractor for the performance of Tenant's Work as set forth in Exhibit D attached hereto); # Tenant's receipt of all necessary permits and approvals from all governmental authorities having jurisdiction over the Premises prior to the construction of the Alterations; # Tenant's delivery to Landlord of such bonds and insurance as Landlord reasonably requires; # Tenant's payment to Landlord of a commercially reasonable fee for Landlord's supervision of any Alterations not to exceed 2% of the cost of the Alterations in question; # Tenant's and Tenant's contractor's compliance with such construction rules and regulations and building standards as Landlord promulgates from time to time; and # Tenant' s delivery to Landlord of “as built” drawings of the Alterations in such form or medium as Landlord may reasonably require.All direct and indirect costs relating to any modifications, alterations or improvements of Building, whether outside or inside of the Premises, required by any governmental agency or by law as a condition or as the result of any Alteration requested or effected by Tenant shall be borne by Tenant. Tenant shall not permit any mechanic's lien or other liens to be placed upon the Premises or the Building as a result of any materials, services or labor ordered by or provided to Tenant or any of Tenant's agents, officers, or employees. Without waiving any other rights or remedies under this Lease, Landlord may bond or insure or otherwise discharge any such lien and Tenant shall reimburse Landlord for any amount paid by Landlord in connection therewith as Additional Rent within ten (10) days after being invoice therefor.

Next results

Draft better contracts
faster with AllDrafts

AllDrafts is a cloud-based editor designed specifically for contracts. With automatic formatting, a massive clause library, smart redaction, and insanely easy templates, it’s a welcome change from Word.

And AllDrafts generates clean Word and PDF files from any draft.