Application of Insufficient Payments. If at any time insufficient funds are received by and available to the Administrative Agent to pay fully all amounts of principal, unreimbursed LC Disbursements, interest and fees then due hereunder, such funds shall be applied # first, towards payment of interest and fees then due hereunder, ratably among the parties entitled thereto in accordance with the amounts of interest and fees then due to such parties, and # second, towards payment of principal and unreimbursed LC Disbursements then due hereunder, ratably among the parties entitled thereto in accordance with the amounts of principal and unreimbursed LC Disbursements then due to such parties.

Shares. Borrower has full power and authority to create a first lien on the Shares, and no disability or contractual obligations exists that would prohibit Borrower from pledging the Shares pursuant to this Agreement. To Borrower’s knowledge, there are no subscriptions, warrants, rights of first refusal or other restrictions on transfer relative to, or options exercisable with respect to the Shares. The Shares have been and will remain duly authorized and validly issued, and are fully paid and non-assessable. To Borrower’s knowledge, the Shares are not the subject of any present or threatened suit, action, arbitration, administrative or other proceeding, and Borrower knows of no reasonable grounds for the institution of any such proceedings.

Shares. Borrower recognizes that Bank may be unable to effect a public sale of any or all the Shares, by reason of certain prohibitions contained in federal securities laws and applicable state and provincial securities laws or otherwise, and may be compelled to resort to one or more private sales thereof to a restricted group of purchasers which will be obliged to agree, among other things, to acquire such securities for their own account for investment and not with a view to the distribution or resale thereof. Borrower acknowledges and agree that any such private sale may result in prices and other terms less favorable than if such sale were a public sale and, notwithstanding such circumstances, agrees that any such private sale shall be deemed to have been made in a commercially reasonable manner. Bank shall be under no obligation to delay a sale of any of the Shares for the period of time necessary to permit the issuer thereof to register such securities for public sale under federal securities laws or under applicable state and provincial securities laws, even if such issuer would agree to do so. Upon the occurrence of an Event of Default which continues, Bank shall have the right to exercise all such rights as a secured party under the Code as it, in its sole judgment, shall deem necessary or appropriate, including without limitation the right to liquidate the Shares and apply the proceeds thereof to reduce the Obligations. Effective only upon the occurrence and during the continuance of an Event of Default, Borrower hereby irrevocably appoints Bank (and any of Bank’s designated officers, or employees) as such Borrower’s true and lawful attorney to enforce such Borrower’s rights against any Subsidiary, including the right to compel any Subsidiary to make payments or distributions owing to such Borrower.

Shares. Pursuant to the Plan, the Company hereby grants to the Participant the right to receive ​ (​,000) shares of the Company’s Common Stock upon the satisfaction of certain conditions (the “Restricted Stock Units”). Shares of the Company’s Common Stock shall be issued only upon vesting of the Restricted Stock Units and only upon the satisfaction of the terms and conditions set forth herein and in the Plan (such shares shall be referred to hereafter as the “Award Stock”).

be delivered to me (or to my beneficiary(ies)) on the deferral date(s) chosen in 2 and 3 above. I acknowledge and agree that in the event that an insufficient number of Shares are available under the Plan, cash will be delivered to me in lieu of Shares.

Builder Notice of Insufficient Progress. If the actual progress of the Work in comparison to the Project Schedule indicates that the Work is not substantially on schedule as set out in the Project Schedule and that the completion of the Vessel by its Delivery Date is in jeopardy, then Builder shall promptly notify Owner and provide a proposed revision to the Project Schedule with such adjustments to sequencing or allocation of resources as may be commercially reasonable to overcome such delays and complete the Vessel by the Delivery Date or as soon thereafter as reasonably practicable.

Monetary Damages Insufficient/Specific Performance. The Company and Indemnitee agree that a monetary remedy for breach of this Agreement may be inadequate, impracticable and difficult of proof, and further agree that such breach may cause Indemnitee irreparable harm. Accordingly, the parties hereto agree that Indemnitee may enforce this Agreement by seeking injunctive relief and/or specific performance hereof, without any necessity of showing actual damage or irreparable harm (having agreed that actual and irreparable harm will result in not forcing the Company to specifically perform its obligations pursuant to this Agreement) and that by seeking injunctive relief and/or specific performance, Indemnitee shall not be precluded from seeking or obtaining any other relief to which he may be entitled. The Company and Indemnitee further agree that Indemnitee shall be entitled to such specific performance and injunctive relief, including temporary restraining orders, preliminary injunctions and permanent injunctions, without the necessity of posting bonds or other undertaking in connection therewith. The Company acknowledges that in the absence of a waiver, a bond or undertaking may be required of Indemnitee by the Court, and the Company hereby waives any such requirement of a bond or undertaking.

When an event occurs in connection with the Awards (e.g., vesting) that the Company determines results in any federal, state, local or foreign tax withholding obligations, (“tax withholding obligations”), to the extent permitted by [Section 409A] and applicable law, the Company may retain without notice from Shares issuable under the Awards or from salary or other amounts payable to you, whole Shares or cash having a value sufficient to satisfy your tax withholding obligations, as set forth in the Plan; provided that such tax withholding obligations shall be satisfied by: first, retaining Shares issuable under the Awards; second, to the extent such Shares are insufficient, retaining any cash payable under the Awards; and third, to the extent the foregoing amounts are insufficient, retaining salary or other amounts payable to you.

If an Event of Default has occurred and is continuing, in the event Grantor receives any dividends, interest or distributions on any Pledged Shares, then # such dividends, interest or distributions and securities or other property shall be included in the definition of Collateral without further action and # upon receipt of written notice from Secured Party to Grantor, Grantor shall promptly take all steps, if any, necessary to ensure the validity, perfection, priority and, if applicable, control of the Secured Party over such Pledged Shares and pending any such action Grantor shall be deemed to hold such dividends, interest, distributions, securities or other property in trust for the benefit of the Lender and shall segregate such dividends, distributions, Securities or other property from all other property of Grantor.

Shares Authorized. Subject to adjustment as described below, the aggregate number of shares of Company common stock, par value $0.001 per share (“Company Stock”), that may be issued or transferred under the Plan is 20,000,000 shares of Company Stock. The aggregate number of shares of Company Stock that may be issued or transferred under the Plan pursuant to Incentive Stock Options shall not exceed 20,000,000 shares of Company Stock.