The Lender agrees to indemnify and hold harmless the Company, its affiliates and their respective officers, directors, employees, agents and controlling persons (collectively, the “Company Indemnified Parties”) from and against, any and all Loss suffered or incurred by any Company Indemnified Party by reason of any misrepresentation or breach of warranty by the Lender or, after any applicable notice and/or cure periods, nonfulfillment of any covenant or agreement to be performed or complied with by the Lender under this Agreement; and will promptly reimburse the Company Indemnified Parties for all expenses (including reasonable fees and expenses of legal counsel) as incurred in connection with any Proceedings.

Additional Indemnity. In addition to, and without regard to any limitations on, the indemnification provided for in Section 1, the ​ indemnifies and holds Indemnitee harmless against all Expenses, judgments, penalties, fines, and amounts paid in settlement actually and reasonably incurred by him or her or on his or her behalf if, by reason of his or her Corporate Status, he or she is, or is threatened to be made, a party to, or participant in, any Proceeding (including a Proceeding by or in the right of the ​), including, without limitation, any and all liability arising out of the negligence or active or passive wrongdoing of Indemnitee. The only limitation that will exist on the ​’s obligations pursuant to this Agreement will be that the ​ will not be obligated to make any payment to Indemnitee that is finally determined (under the procedures, and subject to the presumptions, in Sections 6 and 7) to be unlawful.

Owners’ Indemnity. Owners shall indemnify, hold harmless and defend Service Provider, its present and future Affiliates and the respective directors, officers, employees, representatives, agents, shareholders, attorneys, successors and assigns of each of them and all persons or entities claiming through them (collectively referred to as “Service Provider Persons Indemnified”), from and against # all third party claims associated with any injury of or death to natural persons or damage to or destruction of third party property to the extent that such injury, death or damage is proximately caused by or arises out of the negligence or willful misconduct of Owners or their Representatives in the performance or prosecution by Owners or its Representatives of work related to the Project; # any violation of Law to the extent such violation of Law is made by Owners or their Representatives in the performance or prosecution by Owners or their Representatives of work related to the Project; # any and all claims, demands, causes of action, damages, liabilities, losses, penalties, costs and expenses (including reasonable attorneys’ fees) associated with # the Release on or from the Site or any other location of any Hazardous Materials to the extent caused by the negligent acts or negligent omissions or willful misconduct of Owners or their Representatives in the performance or prosecution by Owners or their Representatives of work related to the Project, or # contamination of the environment or injury to natural resources resulting from Hazardous Materials to the extent caused by the negligent acts or omissions or willful misconduct of Owners or their Representatives in the performance or prosecution by Owners or their Representatives of work related to the Project; # all third-party claims of delay, additional work, or other commercial claims, in all such cases arising after the Effective Date, by any third-party contractor having privity with Owners and performing work related to the Project, or by such contractor’s subcontractors, vendors or suppliers, performing work related to the Project; and # all third-party claims of delay, additional work, or other commercial claims, in all such cases arising after the Effective Date, by any third-party contractor having privity with Service Provider under a subcontract or purchase order listed on Exhibit H, Part B or a subcontract or purchase order the Owners direct the Service Provider to assume to permit Service Provider to perform the Services hereunder, or by such contractor’s subcontractors, vendors or suppliers, performing work related to the Project. This Owners’ indemnity obligation shall not apply to any claim arising out of Service Provider’s, its subcontractors’, or their Representatives’ # failure to comply with applicable Law, # reckless or intentionally wrongful conduct, including activities or actions that Service Provider knows are contrary to Owners’ written direction or position, which are not contrary to Law or the terms of this Agreement, or # actions other than those taken pursuant to this Agreement.

Tax Indemnity. Gordon acknowledges and agrees that the Company shall withhold and remit statutory deductions on amounts payable to Gordon under this Agreement. Gordon agrees to indemnify and hold harmless the Company and its directors and officers from any and all liability for tax, penalties, interest or any other amount of any kind whatsoever arising under one or more of the Income Tax Act (Canada), the Employment Insurance Act (Canada), the Canada Pension Plan Act, the Income Tax Act (BC), or any other similar statute of Canada or a province or territory thereof, that arises out of or with respect to any payments made to Gordon pursuant to this Agreement.

Parties' Indemnity. Subject to the terms of this Section, the Parties hereby agree to indemnify, defend and hold harmless the other Party and its officers, directors, agents, attorneys, accountants and affiliates from and against any and all losses, claims, obligations, demands, assessments, penalties, liabilities, costs, damages, reasonable attorneys’ fees and expenses (“Damages”) asserted against or incurred by the Party by reason of or resulting from a breach by the other Party of any representation, warranty or covenant contained herein, or in any agreement executed pursuant thereto.

Seller Indemnity. Seller shall be responsible for, shall pay on a current basis, and shall indemnify, hold harmless, discharge, release, and defend Buyer, all of its Affiliates, successors and assigns, and their respective owners, directors, officers, and other agents from and against any and all liabilities arising from, based upon, related to or associated with the Seller’s ownership of the Leases, to the extent such liabilities are attributable to the period prior to the Closing Date except for rental payments unpaid or due prior to Closing which Seller considers of high importance to pay.

Currency Indemnity. If, for the purposes of obtaining judgment in any court in any jurisdiction with respect to this Agreement or any other Loan Document, it becomes necessary to convert into a particular currency (the “Judgment Currency”) any amount due under this Agreement or under any other Loan Document in any currency other than the Judgment Currency (the “Currency Due”), then conversion shall be made at the rate of exchange prevailing on the Business Day before the day on which judgment is given. For this purpose “rate of exchange” means the rate at which the Administrative Agent is able, on the relevant date, to purchase the Currency Due with the Judgment Currency in accordance with its normal practice at its head office in Toronto, Ontario. In the event that there is a change in the rate of exchange prevailing between the Business Day before the day on which the judgment is given and the date of receipt by the Administrative Agent of the amount due, the Borrower will, on the date of receipt by the Administrative Agent, pay such additional amounts, if any, or be entitled to receive reimbursement of such amount, if any, as may be necessary to ensure that the amount received by the Administrative Agent on such date is the amount in the Judgment Currency which when converted at the rate of exchange prevailing on the date of receipt by the Administrative Agent is the amount then due under this Agreement or such other Loan Document in the Currency Due. If the amount of the Currency Due which the Administrative Agent is so able to purchase is less than the amount of the Currency Due originally due to it, the Borrower shall indemnify and save the Administrative Agent and the Lenders harmless from and against all loss or damage arising as a result of such deficiency. This indemnity shall constitute an obligation separate and independent from the other obligations contained in this Agreement and the other Loan Documents, shall give rise to a separate and independent cause of action, shall apply irrespective of any indulgence granted by the Administrative Agent from time to time and shall continue in full force and effect notwithstanding any judgment or order for a liquidated sum in respect of an amount due under this Agreement or any other Loan Document or under any judgment or order.

General Indemnity. To the extent permitted by law and subject to clause 2.3 below, the Company indemnifies the Director against any liability or loss (including liability for negligence or for legal costs to the maximum extent permitted by law) incurred by the Director:

Environmental Compliance. The Company will, and will cause each Subsidiary to, comply with all Environmental Laws, except where noncompliance could not reasonably be expected to subject the Company or any of its Subsidiaries to liability, individually or in the aggregate, having a Material Adverse Effect. The Company will, and will cause each Subsidiary to, upon the Administrative Agent’s written reasonable request, # cause the performance of such environmental audits and testing, and preparation of such environmental reports, at the Company’s expense, as the Administrative Agent may from time to time reasonably request with respect to any parcel of real Property subject to a Mortgage, which shall be conducted by Persons reasonably acceptable to the Administrative Agent and shall be in form and substance reasonably acceptable to the Administrative Agent, and # permit the Administrative Agent or its representatives to have access to all such real Property for the purpose of conducting, at the Company’s expense, such environmental audits and testing as the Administrative Agent shall reasonably deem appropriate; provided, that if a Phase I or other environmental report with respect to any such parcel of real Property has been completed to the reasonable satisfaction of the Administrative Agent, then no other environmental audits, testing or reports shall be required for such parcel of real Property during the term of this Agreement.

Environmental Assessment. In connection with its surrender of the Premises, Tenant shall submit to Landlord, at least fifteen (15) days prior to the expiration date of this Lease (or in the event of an earlier termination of this Lease, as soon as reasonably possible following such termination), an environmental Assessment of the Premises by a competent and experienced environmental engineer or engineering firm reasonably satisfactory to Landlord (pursuant to a contract approved by Landlord and providing that Landlord can rely on the Environmental Assessment). If such Environmental Assessment reveals that remediation or Clean-up is required under any Environmental Laws that Tenant is responsible for under this Lease, Tenant shall submit a remediation plan prepared by a recognized environmental consultant and shall be responsible for all costs of remediation and Clean-up, as more particularly provided in Section 5.3, above.