Delivery of Premises. Landlord shall deliver possession of the Premises to Tenant upon the date the Base Building Improvements that are required to permit Tenant to enter the Premises for purposes of performing the Tenant Improvement are Substantially Complete (as those terms are defined in the Tenant Improvement Agreement), and Tenant shall accept such delivery of the Premises, without representation or warranty by Landlord, except as expressly provided herein, and with no obligation of Landlord to perform any construction or other work of improvement upon the Premises, or contribute to the cost of any of the foregoing, except as expressly set forth in this Lease, including in the Tenant Improvement Agreement. Landlord shall exercise commercially reasonable efforts (without any obligation to engage overtime labor or commence any litigation) to deliver possession of the Premises to Tenant with the Base Building Improvements Substantially Complete on or before ​. Without limiting the generality of the foregoing, Tenant acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building, or the Project, the suitability of the Premises for Tenant’s use, the condition, capacity or performance of the Base Building Improvements or the identity of other tenants or potential tenants of the Project.

Delivery of the Premises. When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this [Section 3(e)], Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: # any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), # any non-compliance of Landlord’s Work with applicable Legal Requirements, or # any claim that Landlord’s Work was not completed substantially in accordance with the Tl Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period. If contractor fails to remedy such Construction Defect within a reasonable time, Landlord shall use reasonable efforts to remedy the Construction Defect within 30 days unless such Construction Defect cannot reasonably be remedied in 30 days in which case Landlord shall thereafter continue to diligently pursue such remedy.

Premises. ​ does hereby lease to ​, and ​ takes and hires from ​, the premises and improvements constituting the Expansion Space, as depicted on [Exhibit A] attached hereto and made a part hereof, together with all easements, appurtenances, rights and privileges now or hereafter belonging or appurtenant thereto. Upon execution and delivery of this Third Addendum and ​'s delivery of the Expansion Space in two phases as set forth herein, the leased Premises (as that term is used in the Lease) shall contain 90,435 rentable square feet of Floor Area.

Premises. For and in consideration of the rents hereinafter reserved by Landlord and the covenants, terms and agreements hereinafter contained on the part of Tenant, its legal representatives, successors and assigns to be paid, kept and performed, Landlord does hereby demise, lease, rent and let to Tenant and Tenant does hereby take and hire the Premises from Landlord upon and subject to the terms and conditions hereinafter contained. The term “Premises” refers to all the lots described above. The term “Particular Parking Lot” refers to, respectively, each of the following parking lots/areas: # Lots ​ and ​ (Park Row East), # Lots ​ and ​ (Park Row West), and # above-described portion of Lot 20 (Steeple Street).

Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord, subject to the following terms and conditions, the Premises located in the Project and described in the Basic Lease Information and shown on the attached [Exhibit A]. Landlord reserves the right to make such changes, additions and/or deletions to the Project and/or the common areas and parking or other facilities thereof as it shall determine from time to time. Tenant acknowledges that neither Landlord (nor any employee or agent of Landlord) has made any representation or warranty with respect to the suitability or use of the Premises or Project for Tenant’s intended Permitted Use or operations. Landlord shall have no liability to Tenant whatsoever in the event Tenant cannot conduct its Permitted Use and/or intended operations in the Premises and in addition to any other requirements set forth in the Lease, Tenant shall be solely responsible for any and all costs that relate or pertain to alterations necessary or appropriate to make the Premises comply with any codes, regulations, laws or ordinances for such Permitted Use or operations. In addition, Tenant shall provide Landlord with copies of any and all licenses or permits of any kind necessary for it to conduct the Permitted Use at the Premises no later than fifteen (15) days after receipt of the same and upon each subsequent renewal.

Premises. In accordance with [Section 2.2] of the Lease, Landlord has informed Tenant that the actual rentable square footage of the Premises is and shall be 112,298 rentable square feet. Accordingly, Base Rent as set forth in the Lease is hereby deleted and shall be replaced with the following:

Delivery; Acceptance of Premises; Commencement Date. Landlord shall deliver the Premises (“Delivery” or “Deliver”) to Tenant 1 business day after the mutual execution and delivery of this Lease by the parties.

The Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in [Section 2.2] of the Summary (the " XE "Premises" Premises"). The outline of the Premises is set forth in [Exhibit A] attached hereto. The outline of the "Building" and the "Project," as those terms are defined in [Section 1.1.2] below, are further depicted on the Site Plan attached hereto as [Exhibit A-11]1]]. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep and perform each and all of such terms, covenants and conditions by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of [Exhibit A] is to show the approximate location of the Premises only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the "Common Areas," as that term is defined in [Section 1.1.3], below, or the elements thereof or of the accessways to the Premises or the "Project," as that term is defined in [Section 1.1.2], below. Except as specifically set forth in this Lease and in the Tenant Work Letter attached hereto as [Exhibit B] (the " XE "Tenant Work Letter" Tenant Work Letter"), Landlord shall tender possession of the Premises to Tenant in its existing, "as is" condition, and Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. Landlord shall be deemed to have tendered possession of the Premises to Tenant upon the date of delivery of the Substantial Completion Certificate to Tenant in connection with the Tenant Improvements, as those terms are defined in the Tenant Work Letter (the " XE "Possession Date" "Possession Date"), and no action by Tenant shall be required therefor. If Landlord fails to cause the Possession Date to occur on or before ​ (the “ XE "Outside Date" Outside Date”), then Tenant shall be entitled to rent abatement in the amount of one day of Base Rent for each day after the Outside Date that the Possession Date has not occurred. If Landlord fails to cause the Possession Date to occur on or before ​, (" XE "Final Date" Final Date"), then Tenant, at its option, may terminate this Lease by written notice to Landlord. In the event of such termination by Tenant, all sums paid by Tenant to Landlord under this Lease shall be fully refunded to Tenant and neither party shall have any further obligations hereunder. The Outside Date and Final Date shall each be extended by any Tenant Delay (as defined in the Tenant Work Letter) or delays caused by Force Majeure. Landlord shall not be subject to any liability for such failure, and the validity of this Lease shall not be impaired. Neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Tenant's business, except as specifically set forth in this Lease and the Tenant Work Letter. Notwithstanding the foregoing, Landlord shall deliver the Premises to Tenant in good, vacant, broom clean condition, in compliance with Applicable Laws, to the extent required to allow the legal occupancy of the Premises, with the roof water-tight and shall cause the plumbing, electrical systems, fire sprinkler system, lighting, HVAC (hereinafter defined), and all other building systems serving the Premises to be in good operating condition and repair on or before the Lease Commencement Date. Any process utilities shall be provided without warranty, in their currently existing, "as-is" condition.

Rentable Square Feet of Premises. The RSF of the Premises and Building are hereby stipulated to be as set forth in the Summary, and shall not be subject to measurement or modification during the Lease Term.

Condition of the Demised Premises. ​ hereby acknowledges and agrees that # all work and installations heretofore required to be performed or made by Landlord under the Original Lease have been fully performed or made prior to the date hereof; # ​ has inspected the Original Premises and agrees to accept same in its “as is” condition as of the date hereof; # ​ has inspected the 5,003 Expansion Premises and agrees to accept same in its “as is” condition as of the date hereof and Landlord shall not be required to perform any work, make any installations or incur any expense in or with respect to the Original Premises (or any portion thereof) in order to prepare same for continued occupancy by ​ or in or with respect to the 5,003 Expansion Premises (or any portion thereof) in order to prepare same for occupancy by ​ except that Landlord will perform the work and make the installations, at Landlord’s sole cost and expense, and in accordance with the requirements of the Lease (including this Agreement), as set forth on the Floor Plan annexed hereto as [Exhibit A], which work is sometimes hereinafter referred to as the “5,003 Expansion Work”. In connection with the performance of the 5,003 Expansion Work, ​ shall provide Landlord and its contractors with access to the Demised Premises, to the extent necessary, in order to perform the 5,003 Expansion Work. ​ acknowledges and agrees that there shall be no liability to Landlord, and no abatement of the obligations and liabilities of ​ under the Lease, on account of any inconvenience or interference that may result from Landlord’s performance of the 5,003 Expansion Work except to the extent the same arise from or in connection with the gross negligence or willful misconduct of Landlord or its employees, contractors, agents or representatives. To the extent necessary, ​ shall be responsible for moving the furniture and equipment in the Original Premises (at ​'s sole cost and expense) in order to permit Landlord to perform the 5,003 Expansion Work. Landlord shall use commercially reasonable efforts to minimize interference with or disruption of ​’s use of the balance of the Demised Premises while performing the 5,003 Expansion Work.

Notwithstanding any other provision of this Lease or by law, the Landlord may terminate this Lease by giving 90 days’ written notice to the Tenant that the Premises has been sold.

Tenant and its authorized agents shall be granted a license by Landlord to enter upon the Premises prior to the Delivery Date at a time and date determined by Landlord in Landlord reasonable discretion, at Tenant’s sole risk and expense, for the sole purpose of inspecting, surveying and measuring the Premises (and not to conduct any invasive environmental testing of the Premises or to conduct any business of Tenant in the Building or Premises); provided, however, that # prior to entering upon the Premises, Tenant shall furnish to Landlord evidence satisfactory to Landlord that insurance coverages required of Tenant under the provisions of Article 23 are in effect, # and such early entry shall at all times prior to the Delivery Date be subject to Articles 12, 13, 14, 19, 21, 22, 23, 28, 31, 34, 35, 37, 38, 39 and 40 of this Lease; # Tenant shall pay all service and maintenance charges for the Premises attributable to Tenant’s early entry and use of the Premises as reasonably determined by Landlord, except that Tenant shall not be obligated to pay for the cost of utilities supplied to the Premises prior to the Delivery Date, and # prior to entering upon the Premises, Tenant shall have delivered to Landlord an executed original of this Lease and payment in an amount equal to # monthly Base Rent for the first (1st) month of the initial Term, plus # the Security Deposit. In the event of any breach or default by Tenant of any term or provision of those certain Lease sections set forth in [clause (b) above], Landlord may, in its reasonable discretion, in addition to exercising any of its other rights and remedies set forth herein, revoke such early entry license upon written notice to Tenant.

delivery of the New Premises is delayed as a result of Tenant’s failure to provide said insurance certificates, the New Term Commencement Date shall remain unchanged to extent delayed by such failure.

No agreement to accept surrender of all or any part of the Demised Premises shall be valid unless in writing and signed by Landlord. The delivery of keys to an employee of Landlord or of its agent shall not operate as a termination of this lease or a surrender of the Demised Premises. If Tenant shall at any time request Landlord to sublet the Demised Premises for Tenant’s account, Landlord or its agents is authorized to receive said keys for such purposes without releasing Tenant from any of its obligations under this lease.

New Lease; Lease Amendment. If Tenant leases the Station 5 Premises pursuant to this Paragraph 42, Landlord shall prepare, and Landlord and Tenant shall execute within thirty (30) days after Tenant’s delivery of the Expansion Exercise Notice, # a new lease demising the Station 5 Premises on the same terms and conditions of this Lease as modified pursuant to Paragraph 42.3 (for purposes of this Paragraph 42, the “Station 5 Lease”).

Delivery of Shares. The Company shall deliver to the Employee a certificate or certificates, or at the election of the Company make an appropriate book-entry, for the number of shares of Common Stock equal to the number of vested Stock Units as soon as administratively practicable (but always by the 30th day) after the earliest of the Employee’s termination of employment, a Change in Control (but only to the extent provided in [Section 14]) or the Payment Date. The number of shares delivered shall be reduced by the value of all taxes withheld by reason of such delivery; provided that the amount that is withheld, or may be withheld at the Employee’s discretion, cannot exceed the amount of the taxes owed by the Employee using the maximum statutory tax rate in the Employee’s applicable jurisdiction(s). The Employee shall not be entitled to receive any shares of Common Stock with respect to unvested Stock Units, and the Employee shall have no further rights with regard to a Stock Unit once the underlying share of Common Stock has been delivered with respect to that Stock Unit.

Execution and Delivery. This Amendment and the other Loan Documents being executed and delivered in connection with this Amendment to which it is, or is to become, a party have been or will be (as the case may be) duly executed and delivered by it, and each of this Amendment and the Amended Agreement is, and upon execution and delivery thereof each such other Loan Document will be, the legal, valid and binding obligation of it enforceable against it in accordance with its terms, subject, however, to the application by a court of general principles of equity and to the effect of any applicable bankruptcy, insolvency, reorganization, moratorium or similar laws affecting creditors’ rights generally.

Delivery of Shares. The Company shall, within thirty (30) days of each vesting date above, make prompt delivery of a certificate or book entry statement evidencing such whole shares of Common Stock subject to this Grant plus a check for cash representing all accrued dividends on said stock through such date to the Participant, provided that if any law or regulation requires the Company to take any action with respect to such certificate before the issuance thereof, then the date of delivery of such certificate shall be extended for the period necessary to complete such action. No shares shall be issued and delivered upon exercise of this Grant unless and until, in the opinion of counsel for the Company, any applicable registration requirements of the Securities Act of 1933, any applicable listing requirements of any national securities exchange on which stock of the same class is then listed, and any other requirements of law or of any regulatory bodies having jurisdiction over such issuance and delivery, shall have been complied with.