Delivery. Time is of the essence of this Order. If Seller delivers (he goods later than scheduled, Buyer may assess the following amounts as liquidated damages for the delay period; provided however, if Seller is […​…] liquidated damages may be assessed. Where Seller is […​…], Seller shall pay to Buyer an amount equal to […​…] (“LD Cap”). For the avoidance of doubt, in determining any liquidated damages delay period, good deliveries pursuant to this Order shall be applied sequentially to the scheduled delivery dates on a first-in, first-out basis, with each good delivered allocated first to the earliest open scheduled good delivery date. The parties agree that the above amounts, arc for damages resulting from the delay period only; are a reasonable pre estimate of such damages Buyer will suffer as a result of delay based on circumstances existing at the time this Order was issued; and are to be assessed as liquidated damages and not as a penalty. In addition to the Liquidated Damages set forth above, Seller agrees to pay the costs actually incurred by the Buyer in transportation over and above normal transportation costs, up to a maximum of […​…], during the period of time starting […​…] after the delivery date. Except as otherwise set forth in the Supply Agreement, Buyer’s sole remedy for damages for late delivery during the delay period shall be limited to the receipt of the amount of the LD Cap from Seller until […​…] after the LD Cap has been reached after which Buyer may avail itself of any other remedies for breach that exist in this Order (including termination for Seller’s breach of its delivery obligations). Notwithstanding anything herein to the contrary, and without limiting Buyer’s other rights herein, no liquidated damages shall apply to laic delivery during calendar year […​…]. All delivery designations are INCOTERMS 2010. Unless otherwise stated on the face of this Order, all goods provided under this Order shall be FCA Storage Yard. Notwithstanding the foregoing Incoterm, Seller shall not be responsible for clearing the goods for export.

Date. Whenever any payment due hereunder shall fall due on a day other than a Business Day, such payment shall be made on the next succeeding Business Day, and such extension of time shall be included in the computation of interest or fees, as the case may be.

Prospectus Delivery. Immediately prior to execution of this Agreement, the Company shall have delivered to the Buyer, and as soon as practicable after execution of this Agreement the Company shall file, Prospectus Supplements with respect to the Securities to be issued on the Closing Date, as required under, and in conformity with, the 1933 Act, including Rule 424(b) thereunder. The Company shall provide the Buyer a reasonable opportunity to comment on a draft of each Prospectus Supplement and any Issuer Free Writing Prospectus, shall give due consideration to all such comments and, subject to the provisions of Section ‎4(b) hereof, shall deliver or make available to the Buyer, without charge, an electronic copy of each form of Prospectus Supplement, together with the Prospectus, and any Permitted Free Writing Prospectus on the Closing Date. The Company consents to the use of the Prospectus (and of any Prospectus Supplements thereto) in accordance with the provisions of the 1933 Act and with the securities or “blue sky” laws of the jurisdictions in which the Securities may be sold by the Buyer, in connection with the offering and sale of the Securities and for such period of time thereafter as the Prospectus (or in lieu thereof, the notice referred to in Rule 173(a) under the 1933 Act) is required by the 1933 Act to be delivered in connection with sales of the Securities. If during such period of time any event shall occur that in the judgment of the Company and its counsel is required to be set forth in the Registration Statement or the Prospectus or any Permitted Free Writing Prospectus or should be set forth therein in order to make the statements made therein (in the case of the Prospectus, in light of the circumstances under which they were made) not misleading, or if it is necessary to amend the Registration Statement or supplement or amend the Prospectus or any Permitted Free Writing Prospectus to comply with the 1933 Act or any other applicable law or regulation, the Company shall forthwith prepare and, subject to Section ‎4(b) above, file with the SEC an appropriate amendment to the Registration Statement or Prospectus Supplement to the Prospectus (or supplement to the Permitted Free Writing Prospectus) and shall expeditiously furnish or make available to the Buyer an electronic copy thereof.

Electronic Delivery. The Company may, in its sole discretion, deliver any documents related to the DSUs and Grantee’s participation in the Plan, or future awards that may be granted under the Plan, by electronic means. Grantee hereby consents to receive such documents by electronic delivery and, if requested, agrees to participate in the Plan through an online or electronic system established and maintained by the Company or another third party designated by the Company.

Electronic Delivery. The Company may, in its sole discretion, decide to deliver any documents related to the Shares subject to this Award by electronic means. Participant hereby consents to receive such documents by electronic delivery through any on-line or electronic system established and maintained by the Company or a third party designated by the Company.

Delivery Location. The Aircraft shall be located at the agreed Delivery Location;

Execution; Delivery. This Second Amended Agreement may be executed in one or more counterparts and by different Parties on separate counterparts, each of which will be deemed an original, but all of which together will constitute one and the same instrument. Delivery of an executed counterpart by facsimile or emailed PDF file (to ​ for IGI; to Jean Marie Breen ​ for PBGC) will be equally as effective as delivery of an original executed counterpart.

Prospectus Delivery. ​ consents to the use of the Prospectus (and of each Prospectus Supplement thereto) in accordance with the provisions of the Securities Act and with the securities or “blue sky” laws of the jurisdictions in which the Purchase Shares may be sold by ​, in connection with the offering and sale of the Purchase Shares and for such period of time thereafter as the Prospectus is required by the Securities Act to be delivered in connection with sales of the Purchase Shares. ​ will make available to ​ upon request, and thereafter from time to time will furnish to ​, as many copies of the Prospectus (and each Prospectus Supplement thereto) as ​ may reasonably request for the purposes contemplated by the Securities Act within the time during which the Prospectus is required by the Securities Act to be delivered in connection with sales of the Purchase Shares. If during such period of time any event shall occur that in the reasonable judgment of ​ and its counsel, or in the reasonable judgment of ​ and its counsel, is required to be set forth in the Registration Statement, the Prospectus or any Prospectus Supplement or should be set forth therein in order to make the statements made therein (in the case of the Prospectus or any Prospectus Supplement, in light of the circumstances under which they were made) not misleading, or if in the reasonable judgment of ​ and its counsel, or in the reasonable judgment of ​ and its counsel, it is otherwise necessary to amend the Registration Statement or supplement the Prospectus or any Prospectus Supplement to comply with the Securities Act or any other applicable law or regulation, ​ shall forthwith prepare and, subject to [Section 5(k)] above, file with the SEC an appropriate amendment to the Registration Statement or an appropriate Prospectus Supplement and in each case shall expeditiously furnish to ​, at ​’s expense, such amendment to the Registration Statement or such Prospectus Supplement, as applicable, as may be necessary to reflect any such change or to effect such compliance. ​ shall have no obligation to separately advise ​ of, or deliver copies to ​ of, the SEC Documents, all of which ​ shall be deemed to have notice of.

Counterparts; Delivery. This Amendment may be executed in counterparts (and by different parties hereto in different counterparts), each of which shall constitute an original, but all of which when taken together shall constitute a single contract. Delivery of an executed counterpart of this Amendment by facsimile or other electronic imaging means shall be effective as an original.

Delivery Timeline. If ​ fails to deliver to ​ such certificate or certificates (or shares through the DWAC program) pursuant to this Section (free of any restrictions on transfer or legends, if eligible) prior to 3 Trading Days after the Conversion Date, ​ shall pay to ​ as liquidated damages an amount equal to ​ per day, until such certificate or certificates are delivered. ​ acknowledges that it would be extremely difficult or impracticable to determine ​’s actual damages and costs resulting from a failure to deliver the Common Stock and the inclusion herein of any such additional amounts are the agreed upon liquidated damages representing a reasonable estimate of those damages and costs. Such liquidated damages will be automatically added to the Principal Sum of the Note and tack back to the Effective Date for purposes of Rule 144.