If the agreed delivery date is delayed due to reasons attributable to BOSCH, the date for the contractual penalty shall be postponed accordingly. SUPPLIER shall notify all delays in writing without delay to the ordering Purchasing Department of BOSCH. This also applies if, as a result of the option being exercised after the agreed upon order date, a new delivery date is agreed.

Delivery; Acceptance of Premises; Commencement Date. Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: # the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), and any prepaid Base Rent shall be returned to Tenant within 30 days thereafter, and # neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.

any defense or judicial intervention by Borrower, Guarantor or their respective Affiliates which is asserted in bad faith (as determined by a final, non-appealable order of a court of competent jurisdiction) that delays, impedes, obstructs, hinders, enjoins or otherwise materially interferes with or frustrates the efforts of Lender to exercise any rights and remedies available to Lender as provided in the Loan Documents;

Angelman Syndrome is a rare genetic neurological disorder characterized by profound developmental delays, intellectual disability, problems with motor coordination and balance, seizures, sleep disturbances, and severe speech impairment. According to the Foundation for Angelman Syndrome Therapeutics (FAST), approximately 1 in 15,000 live births have Angelman Syndrome, with an estimated 4,000 patients in the United States. There are no therapeutic agents approved to treat Angelman Syndrome.

then, notwithstanding anything to the contrary set forth in the Lease or this Tenant Work Letter and regardless of the actual date of the Substantial Completion of the Improvements in the New Premises, the date of Substantial Completion thereof shall be deemed to be the date that Substantial Completion would have occurred if no Tenant Delay or Delays, as set forth above, had occurred.

Notwithstanding the foregoing to the contrary, if Landlord has not delivered vacant and exclusive possession of any Offer Space to Tenant on or before the date that is twelve (12) months following the applicable Anticipated Offer Space Commencement Date (as such date shall be extended due to Unavoidable Delays and/or Tenant Delays), then Tenant shall be entitled to terminate this Lease with respect to such Offer Space only upon thirty (30) days’ notice to Landlord, and upon the expiration of such 30 days, this Lease shall terminate with respect to such Offer Space only (unless Landlord has caused vacant and exclusive possession of such Offer Space to have been delivered to Tenant prior to the expiration of said 30 days), and, upon such termination, neither party shall have any further obligations to the other hereunder with respect to such Offer Space except for any rights or obligations that expressly survive the termination of the Lease with respect to such Offer Space.

the Company directs its transfer agent not to transfer, or delays, impairs, or hinders its transfer agent in transferring or issuing (electronically or in certificated form) any certificate for Shares of Common Stock to be issued to the Holder upon conversion of or otherwise pursuant to this Note as and when required by this Note, or fails to remove (or directs its transfer agent not to remove or impairs, delays and/or hinders its transfer agent from removing) any restrictive legend (or to withdraw and stop transfer instructions) on any certificate for any Shares of Common Stock issued to the Holder upon conversion of or otherwise pursuant to this Note as and when required by this Note (or makes any written announcement, statement or threat that it does not intend to honor its obligations pursuant to a Conversion Notice submitted by the Holder) and any such failure shall continue uncured for three (3) Business Days after the Conversion Notice has been delivered to the Company by Holder,

Fees. As agreed, we will forward our bills for this matter to you. We understand that you will be responsible for payment. Our policy is to bill each client monthly for all services performed and expenses incurred in the previous month. Since there are sometimes delays in the accrual of expenses, they will occasionally be included in a subsequent billing. Payment of our billing statements is due in full on receipt.

subject to excusable delays due to acts of god, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages or shortages of labor or materials, the Restoring Borrower shall commence Restoration as soon as reasonably practicable (but in no event later than sixty (60) days after such Casualty or Condemnation, whichever the case may be, occurs) and shall diligently pursue the same to satisfactory completion;

The initial annual Base Rent payable by ​ under this Lease shall be equal to seven and one-half percent (7.5%) times the lesser of (i) the actual amount of Total Development Costs (defined below) incurred in connection with the development of the Property, and (ii) the amount of Total Development Costs set forth in the Final Total Development Cost Budget plus any increase in Total Development Costs from the amount thereof set forth in the Final Total Development Cost Budget incurred as a result of ​ Delays or Changes.