Delay. No failure or delay on the part of any party in exercising any right, power or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right, power or remedy preclude any other or further exercise thereof or the exercise of any other right, power or remedy. The remedies provided for herein are cumulative and are not exclusive of any remedies that may be available to a party at law or in equity or otherwise.

Delay Rights. Notwithstanding anything to the contrary contained herein, the Company may, upon notice to any Selling Holder whose Registrable Securities are included in a Registration Statement, suspend such Selling Holder’s use of any prospectus which is a part of such Registration Statement (in which event the Selling Holder shall suspend sales of the Registrable Securities pursuant to such Registration Statement) if # the Company is pursuing a material acquisition, merger, reorganization, disposition or other material transaction and the Company determines in good faith that the Company’s ability to pursue or consummate such a transaction would be materially and adversely affected by any required disclosure of such transaction in such Registration Statement, or # the Company or any of its Affiliates has experienced some other material non-public event, the disclosure of which at such time, in the good faith judgment of the Company, would materially and adversely affect the Company; provided, however, that in no event shall the Selling Holders be suspended from selling Registrable Securities pursuant to such Registration Statement # during the 30-day period following the applicable Installment Payment Date, or # for a period that exceeds an aggregate of 60 days in any 180-day period or 90 days in any 365-day period, and there shall not be less than 30 days between any two such suspensions. Upon disclosure of such information or the termination of the condition causing any suspension, the Company shall promptly provide notice to the Holders whose Registrable Securities are included in such Registration Statement, and shall promptly terminate any suspension of sales it has put into effect and shall take such other actions necessary or appropriate to permit the Holders to resume sales of Registrable Securities under the Registration Statement. Notwithstanding the foregoing, if on the applicable Determination Date, the Company has knowledge that either [clause (i) or (ii) of this Section 3.01(b)] would trigger such delay rights with respect to an Installment Payment, then the Company shall cause the Buyer to elect on the applicable Determination Date to make such Installment Payment in cash to TEG under the Purchase Agreement.

Landlord Delay. A “Landlord Delay” shall be defined as any act or wrongful omission by Landlord or any agent, employee, consultant, contractor or subcontractor of Landlord which causes an actual delay in the Substantial Completion of Tenant’s ES Fitout. Notwithstanding the foregoing, no event shall be deemed to be a Landlord Delay until and unless Tenant has given Landlord written notice (the “Landlord Delay Notice”) advising Landlord # that a Landlord Delay is occurring, # of the basis on which Tenant has determined that a Landlord Delay is occurring, and # the actions which Tenant believes that Landlord must take to eliminate such Landlord Delay, and Landlord has failed to dispute such asserted delay or to correct the Landlord Delay specified in the Landlord Delay Notice within three (3) business days following receipt thereof. No period of time prior to expiration of such 3-business day period shall be included in the period of

Delivery. Not later than the fifth (5th) business day following the date of this Lease (the “Delivery Date”), [[Organization A:Organization]] shall deliver the Premises to [[Organization B:Organization]] in its “as is” condition. Failure of [[Organization A:Organization]] to deliver possession of the Premises by the Delivery Date, due to a holding over by a prior [[Organization B:Organization]] or any other cause beyond [[Organization A:Organization]]'s control shall not subject the [[Organization A:Organization]] to liability, except that for each day after the Delivery Date that [[Organization A:Organization]] does not deliver the Premises to [[Organization B:Organization]], the Commencement Date shall be extended by one (1) day. In addition, If the Delivery Date has not occurred by December 1, 2017, [[Organization B:Organization]] may elect to terminate this Lease upon written notice to [[Organization A:Organization]], in which case the Security Deposit and amount deposited in escrow for Liquidated Damages pursuant to [Section 37] shall be promptly returned to [[Organization B:Organization]]. On the date that [[Organization A:Organization]] actually delivers the Premises to [[Organization B:Organization]], [[Organization A:Organization]] shall deliver a written notice to [[Organization B:Organization]] memorializing such delivery.

Delivery. This Agreement may be executed in multiple counterparts (each of which shall be deemed an original, but all of which together shall constitute one and the same instrument). Signatures to this Agreement transmitted by facsimile transmission, by electronic mail in “portable document format” (.pdf) form, or by any other electronic means intended to preserve the original graphic and pictorial appearance of a document, shall have the same effect as physical delivery of the paper document bearing the original signature.

Delivery. Landlord shall deliver the Expansion Premises to Tenant in vacant, broom clean condition and otherwise in substantially the same condition in which the Expansion Premises are in as of the date of this First Amendment excluding any personal property of Omniox (except to the extent that Tenant or any Tenant Party is responsible for any changes in such condition of the Expansion Premises) (“Delivery” or “Deliver”) on or before the Target Expansion Premises Commencement Date. The “Target Expansion Premises Commencement Date” shall be November 1, 2015. If Landlord fails to timely Deliver the Expansion Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this First Amendment shall not be void or voidable except as provided herein. If Landlord does not Deliver the Expansion Premises within 90 days of the Target Expansion Premises Commencement Date for any reason other than Force Majeure delays, then the Lease with respect to the Expansion Premises only may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: # the additional Security Deposit delivered pursuant to Section 7 of this First Amendment, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of the Lease), shall be returned to Tenant, and # neither Landlord nor

Delivery. All Product shall be delivered ​ (as defined by Incoterms® 2020). Lonza shall deliver to Customer the Certificate of Analysis and such other documentation as is reasonably required to meet all applicable regulatory requirements of the Governmental Authorities not later than the date of delivery of Batches (the “Release”). ​. In addition, Lonza shall exercise reasonable commercial efforts and customary due diligence and care to ensure that Customer Supplier Raw Materials and Customer Product Components are stored in accordance with the Specifications, cGMPs, Quality Agreement and Customer’s instructions and protect these from theft, casualty, or other damage within Lonza’s reasonable control.

Delivery. [[Organization A:Organization]] shall deliver all Products F.O.B. at [[Organization A:Organization]]’s shipping point for delivery to [[Organization B:Organization]]'s facility as specified in the Purchase Order. Title and risk of loss will transfer from [[Organization A:Organization]] to [[Organization B:Organization]] upon delivery of Product to [[Organization B:Organization]]’s shipment carrier. [[Organization B:Organization]] shall provide instruction on when the product is to be delivered, and how much product is to be picked up each month. The [[Organization B:Organization]] shall be responsible for shipping costs from the [[Organization A:Organization]]’s shipping point.

Delivery. As promptly as practicable after receipt of the Notice, the Investment Letter (if required) and payment, the Company shall deliver or cause to be delivered to the optionee certificates for the number of shares with respect to which such Option has been so exercised, issued in the optionee’s name; provided, however, that such delivery shall be deemed effected for all purposes when the Company or a stock transfer agent shall have deposited such certificates in the United States mail, addressed to the optionee, at the address specified in the Notice.

Delivery. Time is of the essence of this Order. If Seller delivers (he goods later than scheduled, Buyer may assess the following amounts as liquidated damages for the delay period; provided however, if Seller is […​…] liquidated damages may be assessed. Where Seller is […​…], Seller shall pay to Buyer an amount equal to […​…] (“LD Cap”). For the avoidance of doubt, in determining any liquidated damages delay period, good deliveries pursuant to this Order shall be applied sequentially to the scheduled delivery dates on a first-in, first-out basis, with each good delivered allocated first to the earliest open scheduled good delivery date. The parties agree that the above amounts, arc for damages resulting from the delay period only; are a reasonable pre estimate of such damages Buyer will suffer as a result of delay based on circumstances existing at the time this Order was issued; and are to be assessed as liquidated damages and not as a penalty. In addition to the Liquidated Damages set forth above, Seller agrees to pay the costs actually incurred by the Buyer in transportation over and above normal transportation costs, up to a maximum of […​…], during the period of time starting […​…] after the delivery date. Except as otherwise set forth in the Supply Agreement, Buyer’s sole remedy for damages for late delivery during the delay period shall be limited to the receipt of the amount of the LD Cap from Seller until […​…] after the LD Cap has been reached after which Buyer may avail itself of any other remedies for breach that exist in this Order (including termination for Seller’s breach of its delivery obligations). Notwithstanding anything herein to the contrary, and without limiting Buyer’s other rights herein, no liquidated damages shall apply to laic delivery during calendar year […​…]. All delivery designations are INCOTERMS 2010. Unless otherwise stated on the face of this Order, all goods provided under this Order shall be FCA Storage Yard. Notwithstanding the foregoing Incoterm, Seller shall not be responsible for clearing the goods for export.