DRAWINGS. Any review or approval of drawings by Buyer will be for Seller’s convenience and will not relieve Seller of its responsibility to meet all requirements of ibis Order.

Working Drawings. Landlord shall cause the Tl Architect to prepare and deliver construction plans, specifications and drawings for the Tenant Improvements (“Tl Construction Drawings”) consistent with the Space Plans and the Tl Specifications.

Schedule. Landlord shall deliver to Tenant a reasonably detailed schedule setting forth milestone dates for Substantial Completion of the Base Building Improvements, and shall keep Tenant reasonably apprised of any material changes in said schedule.

Final Working Drawings. After the Preliminary Plans have been approved by Landlord, Tenant shall cause Tenant’s Architect and the Engineers to prepare and submit for Landlord’s approval complete and detailed construction plans and specifications, including a fully coordinated set of architectural, structural, mechanical, fire protection, electrical and plumbing working drawings for the Tenant Improvement Work, in a form that is sufficiently complete to permit subcontractors to bid on the work, obtain all required Permits (as defined in [Section 3.4], below) and commence construction (the “Final Working Drawings”). The Tenant Improvements shall be designed in accordance with the LEED Design/Operational Requirements and the Final Working Drawings shall incorporate the LEED Design/Operational Requirements. Tenant shall furnish Landlord with two (2) hard copies signed by Tenant and one (1) electronic version of such Final Working Drawings. Landlord shall approve or disapprove the Final Working Drawings by giving written notice to Tenant within fifteen (15) Business Days after receipt thereof. Landlord shall not unreasonably withhold its approval of the Final Working Drawings, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Final Working Drawings for any of the reasons specified in [Section 2.2.1] above, or if in Landlord’s good faith judgment, the Final Working Drawings are inconsistent with, or do not conform to, the Approved Preliminary Plans. If Landlord disapproves the Final Working Drawings, Landlord shall return the Final Working Drawings to Tenant with a statement of Landlord’s reasons for disapproval and/or specifying any required corrections or revisions. Landlord shall approve or disapprove of any such revisions to the Final Working Drawings within seven (7) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Final Working Drawings (as so approved, the “Approved TI Construction Drawings”). Tenant shall include provisions in it Design Professional Agreements (as defined in [Section 2.2.4]) which expressly allow Landlord to use any and all of the Approved TI Construction Drawings for the Tenant Improvements without any additional cost or payment if the Lease is terminated, subject to Landlord agreeing to indemnify Tenant’s Architect and Engineers in question if Landlord elects to use any of the Approved TI Construction Drawings without retaining Tenant’s Architect or Engineer for the portion of Tenant’s Work covered by the Design Profession Agreement in question.

#​’s Work. ​ shall cause the Architect to prepare and submit to ​ after approval of the Base Building Schematics those sets of construction drawings for the ​’s Work referred to in the Progress Schedule, e.g. the design development package, permit submittal package, etc. (each a “Base Building Construction Document Package”), which shall include two (2) prints and electronic files of the relevant construction drawings for the ​’s Work, each of which shall be consistent with the Base Building Schematics, and shall provide further design detail for the ​’s Work. ​ shall review and approve each Base Building Construction Document Package in accordance with [Section 2.7], and the Base Building Construction Document Packages approved (or deemed approved) by ​ shall be referred to collectively as the “Base Building Construction Documents.” Upon completion of the bid package for the ​’s Work (as described in the Progress Schedule), ​ shall update the SD Total Development Cost Estimate with ​’s then-current estimate of the Total Development Costs for the Premises (the “CD Total Development Cost Estimate”); and in the event that any line-item in such CD Total Development Cost Estimate exceeds the corresponding line-item in the SD Total Development Cost Estimate, ​ shall provide a reasonably detailed description of the basis for such increase and if there is an aggregate increase from the SD Total Development Cost Estimate to the CD Total Development Cost Estimate, the CD Total Development Cost Estimate shall be subject to ​’s reasonable review and approval, which approval shall be given or withheld within five (5) business days following ​’s delivery of the CD Total Development Cost Estimate.

Changes to Construction Drawings. Tenant shall have the right to request changes in or to the Construction Drawings so long as such request is in writing and is provided to both the Construction Manager and Landlord (and not to Landlord’s Architect or Contractor). After approval by the Construction Manager and Landlord, any such change shall be made by Landlord’s Architect. No change shall be permitted without the prior written consent of Landlord which as to nonstructural changes which do not affect building systems, shall not be unreasonably withheld or delayed. Further, if changes are made by Tenant to the Construction Drawings after Landlord’s and Tenant’s approval thereof, and should these changes to the Construction Drawings cause the Final Pricing to be increased or cause Landlord to postpone Substantial Completion of the space or delay the Expansion Date, then Landlord shall have the right to refuse to permit the making of such changes unless and until Tenant shall have committed in writing, in a manner reasonably satisfactory to Landlord, to pay to Landlord # the extra cost in excess of the Final Pricing and # on the date Rent would have commenced hereunder in the absence of such delay, a sum of money equivalent to the Rent for the Premises for the period during which Tenant would have been obligated to pay Rent to Landlord had not the Expansion Date been so delayed with such delay being considered a “Tenant Delay” hereunder. Tenant shall pay to Landlord within ten (10) days of such final approval, one hundred percent (100%) of such additional costs. Furthermore, if Tenant’s changes to the Construction Drawings will cause Landlord to postpone Substantial Completion of the Leasehold Improvements and Landlord is able to determine such fact at the time such change is requested by Tenant, then Landlord agrees to notify Tenant of such delay at the time Tenant requests such change and Tenant will be entitled within three (3) days of such notice to withdraw its request. Any costs incurred by Landlord in making a change which is later withdrawn by Tenant shall be promptly reimbursed by Tenant to Landlord.

Letter of Credit Drawings. The obligations of the [[Organization A:Organization]] under this Agreement and any Letter of Credit Agreement and any other agreement or instrument relating to or any Letter of Credit shall be absolute, unconditional and irrevocable, and shall be paid strictly in accordance with the terms of this Agreement, such Letter of Credit Agreement and such other agreement or instrument under all circumstances, including, without limitation, the following circumstances (it being understood that any such payment by the [[Organization A:Organization]] is without prejudice to, and does not constitute a waiver of, any rights the [[Organization A:Organization]] might have or might acquire as a result of the payment by any [[Organization B:Organization]] of any draft or the reimbursement by the [[Organization A:Organization]] thereof):

[Schedule 8.17] hereto sets forth a complete list of all “business associate agreements” (as such term is defined in HIPAA) that any Borrower or Guarantor has entered into with any person as of the date of Amendment No. 4.

[Schedule 8.18] hereto sets forth an accurate, complete and current list of all participation agreements of any Borrower or Guarantor with health maintenance organizations, insurance programs, preferred provider organizations and other Third Party Payors and all such agreements are in full force and effect and no material default exists thereunder.

[Schedule 4.6(b)] to this Agreement sets forth a complete and accurate description of each of the actions, suits, or proceedings with asserted liabilities in excess of, or that would reasonably be expected to result in liabilities in excess of, $10,000,000 (in excess of insurance coverage therefor provided by an insurer which has not denied coverage therefor) that, as of the Sixth Restatement Effective Date, is pending or, to the knowledge of any Borrower, after due inquiry, threatened against Parent or any of its Restricted Subsidiaries.