Completion of Landlord’s Work. Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, in accordance with the Tl Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises and with a certificate or temporary certificate of occupancy (or an equivalent approval having been issued) for the Premises permitting lawful occupancy of the Premises (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenant’s operations in the Premises) (“Substantial Completion” or “Substantially Complete”). Notwithstanding the foregoing, Landlord’s Work shall not be considered Substantially Completed until the Walk-Through Inspection (as defined below) has been completed. Upon Substantial Completion of Landlord’s Work, Landlord shall require the Tl Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document [[Unknown Identifier]]. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: # to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the Tl Permit); # to comply with any request by Tenant for modifications to Landlord’s Work; # to comport with good design, engineering, and construction practices that are not material; or # to make reasonable adjustments for field deviations or conditions encountered during the construction of Landlord’s Work. Landlord shall provide Tenant notice of any such Minor Variations. For purposes of this Work Letter, “Walk-Through Inspection” shall mean that Landlord and Tenant have together, within 1 business day after request from Landlord to do so, conducted a walk-through inspection of the Premises to create a punch list reasonably acceptable to Landlord and Tenant.

Based on Landlord’s Substantial Completion of the Work in the Building, and remeasurement of the Premises, the parties wish to establish all important dates and modify the Lease as set forth in this Amendment.

Landlord’s Authorized Representative. Landlord designates, as Landlord’s authorized representative (“Landlord’s Authorized Representative”), Maureen McCaffrey as the individual authorized by Landlord to approve on behalf of Landlord all plans, drawings and other matters for which the approval of Landlord is required or contemplated pursuant to this ES Work Letter. Tenant shall not be obligated to respond to or act upon any such item until such item has been initialed or signed or submitted in writing (as applicable) by Landlord’s Authorized Representative. Landlord may change Landlord’s Authorized Representative and/or name additional persons to serve as Landlord’s Authorized Representative (provided that Tenant may rely upon the authorization of any one of such persons) upon one (1) business day’s prior written notice to Tenant. Landlord agrees that Landlord’s Authorized Representative(s) shall be reasonably available to meet and consult with Tenant’s Authorized Representative in person (in the vicinity of the Property) or by phone (at the election of Tenant’s Authorized Representative) upon reasonable prior notice by Tenant.

Offer Completion. The Offer shall have been completed in accordance with the terms hereof and the Proxy Statement.

Completion/Compliance. The Property and lots therein have been completed in full compliance with all terms hereof. All requirements by applicable local, state and federal governmental authorities will have been met or exceeded for the Property and each lot therein, including but not limited to, preliminary and final plat approval, proper construction and availability of fully operational utilities including roads, water, sanitary sewer, storm, sewer with all necessary permits and fully compliant (no violations) with all applicable rules, regulations, and ordinances of applicable authorities, and a written statement from the engineer of record that building permits are obtainable from the appropriate governmental agencies for the construction of single-family houses on the lots. A preliminary and final plat of the development, approved construction drawings from the municipal authority and an “AS BUILT” survey will be provided in “PDF” and “CAD” format to the Buyer as they become available. Each lot pin shall have a flagged wooden lathe to mark the pin location. Provided that Buyer provides Seller adequate and appropriate utility easements over and under the Property, as reasonably determined by Seller, Seller will cause permanent underground electric power and telecommunication facilities (collectively, the “Permanent Utilities”) to be installed and available to the perimeter of each lot within the Property within ninety (90) days after Buyer has poured the slab for a residence on a lot and has given Seller written notice that Buyer is ready for the Permanent Utilities for the lot. This post-closing obligation of Seller to provide Permanent Utilities shall expressly survive Closing for twenty-four (24) months.

the Affiliated/Strategic Assets may only be disposed with the prior approval of HWIC or otherwise pursuant to the terms of this Note. The Affiliated/Strategic Assets and this Note will be permitted to be transferred among the Target Group (which shall be deemed to include any transfer to or deposit in any trust in respect of Funds at Lloyds (FAL)) provided that in respect of the transfer of Affiliated/Strategic Assets:

Substantial Completion. For purposes of this Third Amendment, "Substantial Completion" of the Improvements in the New Premises shall occur upon the completion of construction of the Improvements in the New Premises pursuant to the Approved Working Drawings, with the exception of any punch list items and any tenant fixtures, work-stations, built-in furniture, or equipment to be installed by Tenant.

If Landlord is in default under this Lease and, as a consequence, Tenant recovers a monetary judgment against Landlord, the judgment shall be satisfied only out of # the proceeds of sale received on execution of the judgment and levy against the right, title and interest of Landlord in the Building and the Project, # rent or other income from such real property receivable by Landlord or # the consideration received by Landlord from the sale, financing, refinancing or other disposition of all or any part of Landlord’s right, title or interest in the Building or the Project.

Ready for Occupancy. The Premises shall be deemed “Ready for Occupancy” upon the Substantial Completion of the ​’s Work and the ​ Improvements. For purposes of this Lease, “Substantial Completion” of # the ​ Improvements shall occur upon the completion of construction of the ​ Improvements in the Premises pursuant to the TI Construction Documents, and # the ​’s Work shall occur upon the completion of construction of the ​’s Work pursuant to the Base Building

The Work. Subject to the terms and conditions of this Contract (including any Options), Customer shall procure and the Contractor shall deliver the Rivada Constellation, and the Contractor shall furnish all Deliverable Items and perform the other elements of the Work. The Contractor shall perform the Work, provide all Deliverable Items and implement all activities in accordance with the provisions of this Contract and in accordance with generally accepted space industry standards.