Actual Cost and Equitable Adjustment, Margins. Determinations of “the Contractor’s actual cost” or similar wording or “equitable adjustment” shall be made based on the Contractor’s actual costs (direct and indirect, and in the case of general and administrative and overhead, using Contractor’s published annual general and administrative rates that are used for its government and other customers generally) plus margin (in the case of equitable adjustment) and in a manner consistent with the manner in which the Contractor internally accounts for the actual costs associated therewith generally throughout its programs (and which is subject to review by the independent auditor, under [Article 29]). In each case where the Contract refers to a margin payable to the Contractor or with respect to items acquired from the Contractor or Subcontractors, such margin shall equal the amount specified in the Contract (if any such amount is specified) or where the amount of a margin provided for in the Contract is not so specified, such as in the case of equitable adjustment, the

Equitable Adjustment. In the event that, subsequent to the Effective Time of its Merger with Beeline, the Conversion Price of the Company’s Series F and Series F-1 Preferred Stock is reduced on one or more occasions, pursuant to [Section 5(e)(i)] of the Certificates of Designation of the Company’s Series F and Series F-1 Preferred Stock, with the result that additional shares of Common Stock become issuable upon conversion of the Series F and Series F-1 Preferred Stock (such additional issuable Common shares being, collectively, “Adjustment Shares”), then, in each such event, the Company will issue to Executive shares of Common Stock totaling in number one percent (1%) of the additional Adjustment Shares. Adjustment Securities shall be issued to Executive when required under this [Section 2(e)], regardless of whether Executive remains employed by the Company.

Equitable Adjustment as Sole Remedy. If Customer fails to perform the tasks enumerated in this [Article 4.0] or other material obligations of this Contract in a timely manner, and such failure prevents the Contractor from being able to fulfill any of its obligations in accordance with the terms of this Contract, the Contractor shall be entitled as its sole remedy to an equitable adjustment in the Contract Price and Delivery schedule of any affected Work (which equitable adjustment shall include payment for reasonable work-around plans available to the Contractor). The Contractor shall use reasonable efforts to avoid and/or mitigate the effect of the failure of Customer to perform the tasks enumerated in this [Article 4.0] or other material obligations of this Contract in a timely manner, subject to an equitable adjustment in the Contract Price.

Determinations of “equitable adjustment” with regard to the Delivery Schedule shall mean only schedule delay which cannot be reasonably avoided, to the extent the same is demonstrated in the written analysis referred to in this Article. If there is a tradeoff between cost and schedule delay associated with the matter subject to the equitable adjustment, the written analysis shall set forth such tradeoff as an offer to Customer – in the absence of such an offer, or a demonstration by the Contractor that delay causes an increase in its actual costs, the delay shall not result in an equitable adjustment to the Contract Price. For the avoidance of doubt, a reference in the Contract to “equitable adjustment” without further specification may entail an adjustment in the Delivery Schedule, the Contract Price, and/or in any other contractual provision as may be affected, but consistent with this [Article 1.7].

Cost . The cost to design, permit and construct the Tenant Improvements shall be paid by Landlord. Any and all costs, fees or expenses of any kind or nature that are incurred due to changes requested by Tenant shall be the sole responsibility of Tenant.

ACTUAL PARTICIPATION. Subject to the provisions of the Plan, the Committee may, from time to time, select from all eligible Employees and Nonemployee Directors those to whom Awards shall be granted and shall determine the nature and amount of each Award.

Equitable Relief. In the event the Company determines that you have breached or attempted or threatened to breach any of the Restrictive Covenants, in addition to any other remedies at law or in equity the Company may have available to it, it is agreed that the Company will be entitled, upon application to any court, tribunal or arbitrator of competent jurisdiction, to a temporary restraining order or preliminary injunction (without the necessity of # proving irreparable harm, # establishing that monetary damages are inadequate or # posting any bond with respect thereto) against you prohibiting such breach or attempted or threatened breach by proving only the existence of such breach or attempted or threatened breach.

Equitable Relief. Each Party acknowledges that any breach of their obligations set forth in [Sections 2, 3, 4, 5 and 6]6]6]6]6] may cause irreparable harm to the other Party; therefore, the other Party may have, in addition to any remedies available at law, the right to obtain equitable relief to enforce this Agreement.

Equitable Relief. Employee and Conduent agree that, in the event of breach of this Agreement by Employee, Conduent would be irreparably harmed but the amount of damages to Conduent would be difficult to ascertain. Conduent and Employee agree that in the event of such breach, Conduent shall have the right to an injunction or other equitable relief and to all other appropriate legal remedies, including damages. In the event any lawsuit is brought to enforce any of the provisions of this Agreement, the prevailing party shall be entitled to recover its, Employee’s reasonable attorneys’ fees and cost from the other party.

Equitable Remedies. You acknowledge that: # it would be difficult to calculate damages to the Company from any breach of your obligations under [Sections 15 and 16]6] of this Letter Agreement, # that injury to the Company from any such breach would be irreparable and impracticable to measure, and # that the remedy at law for any breach or threatened breach of the provisions of [Sections 15 and 16]6] of this Letter Agreement would therefore be an inadequate remedy and, accordingly, the Company shall, in addition to all other available remedies set forth herein, be entitled to specific performance, injunctive and other similar equitable remedies without posting bond or proving actual damages.